Download or read book Arbitration and Dispute Resolution in the Resources Sector written by Gabriël A. Moens and published by Springer. This book was released on 2015-05-18 with total page 268 pages. Available in PDF, EPUB and Kindle. Book excerpt: This book provides a comprehensive Australian perspective on the resolution of resources disputes. In particular, it focuses on the use of arbitration, mediation and adjudication in the resources sector. It concentrates on arbitration as the preferred method of dispute resolution, including international commercial and investor-state arbitration. The book offers fascinating insights into the use of arbitration to investment disputes involving resources companies in the African OHADA countries, Australia and other countries. It offers an Australian perspective which will be useful to discerning arbitration scholars and dispute resolvers. In addition, the book provides useful information on how to draft arbitration clauses for resources sector contracts. This publication will be of interest to members of the academic research community and will also appeal to dispute resolution professionals and practitioners.

Download or read book Social License and Dispute Resolution in the Extractive Industries written by Cory H. Kent and published by BRILL. This book was released on 2021-03-01 with total page 235 pages. Available in PDF, EPUB and Kindle. Book excerpt: Social License and Dispute Resolution in the Extractive Industries is a broad collection offering insights from both renowned academics and practitioners on the intersection of international dispute resolution and the social license to operate in the extractive industries.

Download or read book Employment Dispute Resolution and Worker Rights in the Changing Workplace written by Adrienne E. Eaton and published by Cornell University Press. This book was released on 1999 with total page 314 pages. Available in PDF, EPUB and Kindle. Book excerpt: Have the speed, informality, and low cost of the grievance and arbitration system deteriorated? Has the system become too adversarial? Has it lost its problem-solving character? This book examines the nature and degree of change in workplace dispute resolution in the context of ongoing changes in work and in labor relations.The volume begins with an editors' introduction that provides context and offers a political perspective on the current state of dispute resolution in the workplace. The chapters that follow contain critiques of the existing legal framework surrounding mandatory arbitration in the nonunion sector and a review of the empirical literature on nonunion dispute resolution. Employment Dispute Resolution and Worker Rights in the Changing Workplace includes sections on grievance mediation, the status of the grievance procedure in workplaces with extensive worker and/or union participation in decision making, and high-performance workplaces. The study concludes with trends in dispute resolution in the public sector and with the alternative dispute resolution system commonly practiced in the unionized construction industry.

Download or read book International Arbitration in the Energy Sector written by Maxi Scherer and published by Oxford University Press. This book was released on 2018-02-22 with total page 400 pages. Available in PDF, EPUB and Kindle. Book excerpt: Disputes in the energy and natural resources sector are at the heart of international arbitration. With more arbitrations arising in the international energy sector than in any other sector, it is not surprising that the highest valued awards in the history of arbitration come from energy-related arbitrations. Energy disputes often involve complex and controversial issues relating to security, sovereignty, and public welfare. International Arbitration in the Energy Sector puts international energy disputes into a global context, providing broad coverage of different forms and systems of dispute resolution across both renewable and non-renewable sectors. With contributions from leading practitioners, arbitrators, academics, and industry experts from across the globe, the eighteen chapters in the book enable readers to compare the approaches to, and learnings from, energy arbitrations across various legal systems and geographic regions. After outlining the international energy arbitration legal framework, the text delves into a detailed analysis of the problems which regularly arise in practice. These include, among other things, commercial disputes in Part I (e.g. over the upstream oil sector and long-term gas supply contracts), investor-state disputes in Part II (e.g. under the Energy Charter Treaty), and public international law disputes in Part III (e.g. concerning international boundaries and the distribution of natural resources). Alongside recent developments in the international energy sector, attention is given to climate and sustainable development disputes, which raise important questions about enforcing sustainability objectives on individuals, corporations, and states. Backed by analyses of arbitral awards, national court and international tribunal decisions, treaties, and other international legal instruments, as well as current events and news in the energy industry, this text offers a unique contribution to international energy literature and provides insightful commentary on the prevalent issues in the field. It is essential reading for any practitioner or researcher in the energy and natural resources sector.

Download or read book Arbitration of International Mining Disputes written by Henry G. Burnett and published by Oxford International Arbitrati. This book was released on 2017 with total page 0 pages. Available in PDF, EPUB and Kindle. Book excerpt: I. Host states, mining companies, and mining projects -- II. Key risks and disputes associated with international mining projects -- III. Practice and procedure -- IV. Law and applicable principles.

Download or read book International Arbitration in Latin America written by Gloria M. Alvarez and published by Kluwer Law International B.V.. This book was released on 2021-04-08 with total page 462 pages. Available in PDF, EPUB and Kindle. Book excerpt: Energy projects in Latin America are a major contributor to economic growth worldwide. This book is the first to offer a comprehensive, in-depth analysis of specific issues arising from energy and natural resources contracts and disputes in the region, covering a wide range of procedural, substantive, and socio-legal issues. The book also includes how states have shifted from passive business partners to more active controlling players. The book contains an extensive treatment and examination of the particularities of arbitration practice in Latin America, including arbitrability, public order, enforcement, and the complex public-private nature of energy transactions. Specialists experienced in resolving international energy and natural disputes throughout the region provide detailed analysis of such issues and topics, including: state-owned entities as co-investors or contracting parties; role of environmental law, indigenous rights and public participation; issues related to political changes, corruption, and quantification of damages; climate change, renewable energy, and the energy transition; force majeure, hardship, and price reopeners; arbitration in the electricity sector; take-or-pay contracts; recognition and enforcement of awards; tension between stabilization clauses and human rights; mediation as a method for dispute settlement in the energy and natural resources sector; and different comparative approaches taken by national courts in key Latin American jurisdictions. The book also delivers a clear explanation on the impact made to the arbitration process by Covid-19, emerging laws, changes of political circumstances, the economic global trends in the oil & gas market, the energy transition, and the rise of new technologies. This invaluable book will be welcomed by in-house lawyers, government officials, as well as academics and rest of the arbitration community involved in international arbitration with particular interest in the energy and natural resources sector.

Download or read book New Frontiers in Asia Pacific International Arbitration and Dispute Resolution written by Shahla Ali and published by Kluwer Law International B.V.. This book was released on 2020-12-10 with total page 313 pages. Available in PDF, EPUB and Kindle. Book excerpt: International Arbitration Law Library Volume 59 The eastward shift in international dispute resolution has already involved initiatives not only to improve support for international commercial arbitration (ICA) and investor-state dispute settlement (ISDS) but also to develop alternatives such as international commercial courts and mediation. Focusing on these initiatives and their accompanying case law and trends in the Asia-Pacific region, this invaluable book challenges existing procedures and frameworks for cross-border dispute resolution in both commercial and treaty arbitration. Specially assembled for this project, an outstanding team of experienced and insightful arbitrators and scholars describes pertinent developments including: ICA and ISDS in the context of China’s Belt and Road Initiative; the Singapore Convention on Mediation; the shift to virtual hearings and other challenges from the COVID-19 pandemic; mistrust of the application of the rule of law in certain East Asian jurisdictions; growing public concern over ISDS arbitration; tensions between confidentiality and transparency; and potential regional harmonisation of the public policy exception to arbitral enforcement. The contributors chart evolving practices and high-profile cases to make informed observations about where changes are needed, as well as educated guesses about the chances of reforms being successful and the consequences if they are not. The main jurisdictions covered are China, Hong Kong, Japan, Malaysia, India, Australia and Singapore. The first in-depth study of recent trends in dispute resolution practice related to business in the Asia-Pacific region, the book’s practical analysis of new resources for dealing with the increasing competition among countries to become credible regional dispute resolution hubs will prove to be of great value to specialists in the international business law sector. Lawyers will be enabled to make informed decisions on which venue and dispute resolution methods are the most suitable for any specific dispute in the region, and policymakers will confidently assess emerging trends in international dispute resolution policy development and treaty-making.

Download or read book Alternative Dispute Resolution Adr written by Stephen E. Altman and published by DIANE Publishing. This book was released on 1999-02 with total page 86 pages. Available in PDF, EPUB and Kindle. Book excerpt: Contains: reasons for using Alternative Dispute Resolution (ADR); the types of ADR that have made available to employees through procedures other than those under collective bargaining agree., & the extent to which they have put these ADR processes in place; & the results achieved by using ADR. Examines a number of private companies & fed. agencies &: their experiences in planning & implementing ADR processes; the extent to which they evaluated their ADR processes & to which they reported that these processes have been successful in resolving workplace disputes; & the lessons they learned in planning, implementing, & evaluating their ADR processes.

Download or read book Alternative Dispute Resolution in the Energy Sector written by Association for International Arbitration and published by Maklu. This book was released on 2009 with total page 158 pages. Available in PDF, EPUB and Kindle. Book excerpt: In a world held in the grip of economic downfall - with increasing scarcity of energy supplies, plummeting oil prices, rising intra-state energy transit, protectionist natural resources policies, and growing environmental concerns - time and cost are not to be underestimated factors in the choice of a suiting dispute resolution method. This book covers the hot topics related to the Energy Charter Treaty, not only from a theoretical point of view, but also from practical experiences in France, the UK, and Belgium. Moreover, this publication is original in that it addresses the issue of soft law in investment arbitration and includes a fictional case elaborating on the influence of different interest groups in energy disputes.

Download or read book Alternative Dispute Resolution in the Workplace written by E. Patrick McDermott and published by Praeger. This book was released on 1996-09-24 with total page 0 pages. Available in PDF, EPUB and Kindle. Book excerpt: With the explosion of workplace litigation and the skyrocketing costs associated with it, employers in both the private and public sectors are seeking new ways to swiftly and inexpensively resolve disputes with their employees. Alternative dispute resolution (ADR) procedures offer ways to do this and, according to recent reports, more than 100 major corporations have made use of them. Not only are the costs of trying a workplace dispute before a jury avoided, but also due process requirements have been observed. McDermott and Berkeley introduce executives to ADR, how it's done, and its benefits. This book will be interesting and important reading for executives and for legal counsel that may be unfamiliar with ADR. The reader is first introduced to the employment litigation revolution that is sweeping the country. The authors explain the various contextual factors that have caused this rise in litigation, including the Civil Rights Act of 1993, the Family and Medical Leave Act of 1990, and the Americans with Disabilities Act. Given this new legal environment, the book explores how ADR can assist an employer in avoiding or reducing the costs of employment law litigation. The subject of ADR is divided into mandatory and nonmandatory procedures. Finally, the authors discuss how an employer can introduce a binding arbitration procedure that diverts employment litigation from a jury to an arbitrator. Drafting tips and model clauses are included should an organization seek to develop a mediation procedure, arbitration procedure, or both.

Download or read book ADR Arbitration and Mediation written by CIArb and published by Author House. This book was released on 2014 with total page 731 pages. Available in PDF, EPUB and Kindle. Book excerpt: " The various developments and changes in the field of arbitration, coupled with the large sums and important issues which are so often at stake in them, mean that a new book providing a comprehensive overview on the topic from an authoritative source is not merely very welcome: it is positively needed by professionals involved in arbitration and their clients. It is hard to think of an organisation better qualified to sponsor such a book than the Chartered Institute of Arbitrators, with its enormous experience and authority in the field. It is also hard to conceive of a more impressive and well qualified group of contributors to such a book than the list of people who Julio CEsar Betancourt and Jason A. Crook have included in this volume. Lord Neuberger of AbbotsburyPresident of the Supreme Court of the United Kingdom The Chartered Institute of Arbitrators is a learned society that works in the public interest to promote and facilitate the use of alternative dispute resolution (ADR) mechanisms. Founded in 1915 and with a Royal Charter granted in 1979, it is a UK-based institution that has gained international presence in more than 100 countries and has more than 13,000 professionally qualified members around the world. Chartered Institute of Arbitrators 12 Bloomsbury Square London, United Kingdom WC1A 2LP T: +44 (0)20 7421 7444 www.ciarb.org Registered Charity: 803725 International Commercial Arbitration is the fastest growing dispute settlement discipline. The complexities surrounding its regulatory framework combined with an ever-increasing and constantly evolving set of acts, rules, guidelines, protocols, regulations, national legislation, international treaties, and so on may appear daunting at first glance. This ""collection of documents"" or ""supplementary material"" is designed to provide the essential reading for all those who are eager to pursue a career in international arbitration. It will also appeal to arbitration practitioners wishing to have easy access to over 700 pages of arbitration-related resources.""

Download or read book Resolving Disputes by Arbitration written by Catherine Swee Kian Tay and published by NUS Press. This book was released on 1998 with total page 194 pages. Available in PDF, EPUB and Kindle. Book excerpt: In this book, the author explains in simple language how business contracts can be better managed by helping the reader be more aware of the various ways through which disputes may be resolved practically and efficiently, especially by arbitration. It also gives an overview of arbitration and the law, including domestic arbitration and international commercial arbitration, and the key elements and considerations that one should know. Intended for the general reader but should be an equally useful reference for the professional.

Download or read book Alternative Dispute Resolution for Government Contracts written by Donald P. Arnavas and published by Wolters Kluwer. This book was released on 2004-01-01 with total page 298 pages. Available in PDF, EPUB and Kindle. Book excerpt: Alternative Dispute Resolution for Government Contracts from CCH is the only resource that provides a comprehensive treatment of ADR in government contracts. It presents a complete discussion of the various ADR procedures together with their advantages and disadvantages, allowing readers to reach an informed decision as to which ADR mode is most suitable for resolution of a specific dispute. Along with covering the Administrative Dispute Resolution Act of 1996, Executive Orders and other applicable regulations are thoroughly discussed. Alternative Dispute Resolution for Government Contracts covers the "hot" areas of ADR, including confidentiality, conflicts of interest, finality of arbitration awards, enforcement of awards and settlement agreements together with all the relevant citations. It will also help you analyze which type of approach is most effective for each of the main ADR processes and the preparation necessary for all members of an ADR team..

Download or read book Construction Arbitration and Alternative Dispute Resolution written by Renato Nazzini and published by Taylor & Francis. This book was released on 2021-10-21 with total page 471 pages. Available in PDF, EPUB and Kindle. Book excerpt: This book provides comprehensive, rigorous and up-to-date coverage of key issues that have emerged in the first quarter of the 21st Century in transnational construction arbitration and alternative dispute resolution (ADR). Covering four general themes, this book discusses: the increasing internationalisation of dispute resolution in construction law; the increasing reliance on technology in the management of construction projects and construction arbitration/ADR; the increasing prominence of collaborative contracting in construction and infrastructure projects; the increasing importance of contractual adjudication such as dispute boards in construction and infrastructure projects; the increasing prevalence of statutory adjudication mechanisms across the world; and the greater incidence of investment disputes and disputes against States and State entities over construction and infrastructure concessions and agreements. Tapping on their substantial expertise in practice and in research, the contributor team of senior practitioners and academics in the area of construction law and dispute resolution provide readers with information that balances an intellectually rigorous academic contribution against the backdrop of real concerns raised in practice. Construction Arbitration and Alternative Dispute Resolution is an invaluable resource for practitioners in the field, academics in arbitration and construction law, and post-graduate students in construction law and dispute resolution.

Download or read book Mediation in Collective Labor Conflicts written by Martin C. Euwema and published by Springer. This book was released on 2019-05-28 with total page 339 pages. Available in PDF, EPUB and Kindle. Book excerpt: This open access book opens up the black box of mediation in collective conflicts through the analyses and comparisons of various systems. Mediation and related third party interventions such as conciliation and facilitation are discussed as effective prevention and regulation tools for different types of collective labor conflicts. These interventions fit in a new developed five-phase model of collective conflicts in organizations, going from capacity building in latent conflicts, through conciliation, mediation and arbitration in escalating phases, to rebuilding of trust after hot conflicts. The authors promote understanding and discussion with regards to labor mediation systems, presenting comparative research on the perspectives of mediators and users of mediation. This book describes and analyses laws, regulations and practices of mediation in seventeen countries, with a relative strong emphasis on Europe. Part 1 presents theoretical frameworks on conciliation and mediation in collective labor conflicts. Part 2 presents regulations and practices in 12 European countries: Belgium, Denmark, Estonia, France, Italy, Poland, Portugal, Spain, The Netherlands, and the United Kingdom. Part 3 discusses mediation in these collective conflicts in Australia, China, India, South Africa and the USA. Part 4 offers conclusions and ways forward. This book offers analyses, good practices and developments for third party intervention in collective labor conflicts in global and local changing environments. This book is a must-read for policy makers, , social partners at different levels, as well as scholars and practitioners in industrial relations, human resources management and conflict management, particularly conciliators and mediators.

Download or read book Taxmann s Construction Arbitration Delays Disputes Resolution 2021 Edition written by Dr. S.B. Saraswat and published by Taxmann Publications Private Limited. This book was released on 2020-12-14 with total page 48 pages. Available in PDF, EPUB and Kindle. Book excerpt: This book has been conceived to address a particularly pressing aspect of ‘disputes in constructions projects’. It provides a practical guide & follows a very systematic approach, to dispute resolution, through mediation, conciliation and arbitration, under the construction contracts. It covers all aspects of the causes of delay including coverage of delay analysis report, the various disputes, and the arbitration process for satisfactory & faster resolution. This book is based on issues relating to major EPC projects of process industries such as steel, petrochemical, power plants, etc. It also covers issues relating to the infrastructure sector in private and public sectors. This book will be useful for persons involved in construction arbitration, lawyers, project professionals, arbitrators, students and academicians. The Present Publications is the 1st Edition, incorporating analysis of problems of the construction sector and their impact along with analysis of 10 case studies while attempting to cull out the necessary principles involved in the execution of the projects. The key features of this book are as follows: • In the introduction, the current scenario of construction sector has been discussed, along-with the problems faced by them and its impact on country’s growth/GDP. • [Delay Analysis Report] Project finalization & execution has also been briefly addressed, along with detailed description of possible reasons of conflicts and disputes in large projects. It also includes Delay Analysis Report (‘DAR’) detailing all the delays which take place in construction projects. • [Preparation of Claims with Examples] Preparation of claims and counter claims has been elucidated (with examples) along-with organizing the evidence for construction arbitration. • Use of Alternate Dispute Resolution (‘ADR’) mechanism, for dispute resolution has been discussed. • [Case Studies] are provided, that compare the project execution methodology, concerning private and public sectors and the outcomes of projects. • [Simple & Lucid Presentation of Text] Technical, contractual & commercial reasons for delay in projects have been described in simple language, which can be understood by lawyers, arbitrators, and laymen working in the construction industry The contents of the book are as follows: • Impact of disputes in construction sector • Ideal needs of successful project execution • Overview of projects and construction sector in India • Types of construction contracts – Traditional • Projects execution in India – Status • General process of finalization of EPC contract for large projects • Stakeholders in EPC project • Analysis and comparison of salient features of different EPC contracts • Critical examination, comparison and review of major clauses of EPC project contracts • Brutal global impact of COVID-19 • Force majeure in Indian projects due to COVID-19 • Project monitoring & control • Pre-requisites for successful completion of an EPC project • Case studies of project execution detailing the methodology of execution, elements of delay and potentialities of disputes in projects • Conclusions drawn from the case studies of project execution • Common clauses of delays in EPC projects • Preparation of project Delay Reports • Delay analyzing techniques in construction projects • Delay in construction contracts – A Legal View • Construction dispute resolution as per Alternate Dispute Resolution mechanism • Settlement of construction dispute through Negotiation • Settlement of construction dispute through Mediation • Settlement of construction dispute through Conciliation • Settlement of construction dispute through Arbitration • Indian Arbitration and Conciliation (Amendment) Act, 2019 a reflection • Claim in a construction project • Need for evidence in construction arbitration Reviewed by Justice Dipak Mishra | Former Chief Justice of India After reading the book, I am tempted to say that though it focuses on a very prosaic subject, yet there is “something” in it that makes it interesting for the readers. And any reader can find that “something” only after studying the book. It is a must read for the students, practitioners and academicians involved in the field. I so recommend as the author is consistently guided by the motto, “quality speaks for itself”. The author’s intention is to assist and educate. I have deliberately used both the words because I am of the view that this book should be read by some with the vision of an Argus-eyed personality and some should study with humility. The author deals with many facets with admirable precision. One may consider his delineation with regard to the conception of delay. He has commandedly adverted to “Common Causes of delay in EPC Projects”. I am certain that anyone arguing a matter before a Tribunal or Court will be extremely benefitted. The author’s case study has its own impact and reaffirms the old saying “Example is better than Precept”. He believes in the concept “successful project execution is more than a written piece of contract”. This statement by Dr. Saraswat deserves to be a quotation. Reviewed by Justice B.B. Srikrishna | Former Judge | Supreme Court of India Dr. S.B. Saraswat is a technocrat with extensive experience of four decades in public as well as private sector industries in India and abroad. He was actively involved in successful execution of many large projects in Steel, Power and Petroleum sectors. His long experience in their execution has exposed him to various kinds of disputes faced as client and as contractor. This book is the result of his rich experience of dispute resolution by arbitration in the construction industry and reflects his insights on aspects of delays, disputes & their resolution. Apart from general discussion of the arbitral mechanics in such disputes, the book focusses on the nature of construction contracts, the likely pitfalls therein, the force majeure clauses in such contracts, project control and monitoring, common causes of delay in EPC contracts, delay analysis techniques, techniques of ADR, nature of claims, their submission and the evidence required to substantiate the claims in light of the legal provisions of the Arbitration and Conciliation Act, 1996 and other applicable laws. Reviewed by Justice Deepak Verma | Former Judge | Supreme Court of India This book by Dr. S.B. Saraswat encapsulates the following: • The problems of the construction sector and their impact has been analyzed in detail. • First it has been advised that disputes should be resolved mutually among stakeholders failing which mediation and conciliation should be adopted. Procedures for the same have been described in the book. • It is a fact that large construction projects in India are invariably delayed due to a variety of reasons. This book contains all the possible reasons for the delay in the project. Further, the book also spells out an action plan to avoid such delays. • The book has handled the delay analysis through various delay techniques normally adopted as a standard practice. Delay in the projects has been described in a comprehensible manner that can be easily understood by lawyers, arbitrators and laymen working in the construction industry. • The book also analyses 10(ten) case studies while attempting to cull out the necessary principles involved in the execution of the projects. • Preparation of claims has been dealt with in the book and explained with suitable examples. • Utility of evidences to substantiate the claims have been incorporated. • The book discusses ADR techniques like Negotiation, Mediation, Conciliation and Arbitration to resolve construction disputes. Reviewed by Justice A.K. Sikri | Former Judge | Supreme Court of India Understanding the need to have some authentic book to guide and help all the stakeholders, Dr. S.B. Saraswat has laboured to produce the book at hand which specifically takes care of issues relating to construction arbitration. The three major elements in this field as mentioned above, viz., delays in such projects, nature of disputes and the resolution thereof through arbitration are the themes which are very deftly articulated and presented in a manner which can easily be absorbed by the readers. A distinguished feature of the book is that the scope is not confined to use of ADR mechanisms for dispute resolution (which includes mediation as well as arbitration), but contains an in- depth analysis into the causes leading to such disputes. This becomes important to ensure ‘Dispute Avoidance’, wherever possible. In case of disputes, the book acts as a helpful guide for the disputants in the manner in which claims should be preferred or the defences be offered. It also guides the stakeholders the manner in which evidence needs to be organised or supporting the claims or defending the claims.

Download or read book Governing Law and Dispute Resolution in the Oil and Gas Industry written by Eduardo G. Pereira and published by Edward Elgar Publishing. This book was released on 2022-08-23 with total page 0 pages. Available in PDF, EPUB and Kindle. Book excerpt: The oil and gas industry's wide international exposure and constantly changing landscape leave it particularly vulnerable to disputes. As this practical book demonstrates, the risks associated with disputes can be mitigated by parties utilising governing law and dispute resolution clauses in contractual agreements within the sector. Examining a global range of jurisdictions, the book offers clear guidance on the most appropriate choice of law and choice of dispute resolution forum for oil and gas contracts, analysing the key issues and defining the legal contours involved. Key Features: Insightful contributions from over 40 leading practitioners and expert legal scholars Examination of domestic and international case law, with analysis of the local laws of 24 jurisdictions globally Consideration of the future of disputes in the oil and gas industry by tracking the evolution and latest trends of the global energy market Examination of the dispute resolution mechanisms used to mitigate disputes, with a focus on international arbitration as a forum for dispute resolution Discussions of a range of operations in the oil and gas industry, including upstream, midstream and downstream projects, and the various contracts that exist within these Featuring a comparative and practice-oriented perspective, this highly informative book will prove an essential resource for practitioners advising parties concerning contractual agreements in the oil and gas sector, as well as a valuable reference point for scholars of energy law and arbitration.